Welcome to Mahadev Solar Enterprises. By accessing and using our website and our solar energy services, you agree to comply with and be bound by the following Terms and Conditions. Please read them carefully before using our website or engaging our services.
1. Acceptance of Terms
By using this website, requesting a quotation, or purchasing our products and services, you agree to these Terms and Conditions. If you do not agree with any part of these terms, please discontinue the use of our website and services.
2. Services Offered
We provide solar energy solutions, including but not limited to:
- On-grid solar system installation
- Off-grid solar system installation
- Hybrid solar system installation
- Solar water pump installation
- Solar street light installation
- Solar maintenance and repair services
- Solar consultation and site assessment
All services are subject to site feasibility, technical requirements, and applicable government regulations.
3. Quotations and Pricing
All quotations provided by us are based on the information available at the time of estimation and are subject to change without prior notice due to:
- Changes in material costs
- Government taxes and duties
- Site conditions
- Additional customer requirements
A final quotation will be provided after site inspection where applicable.
4. Payment Terms
- Customers must make payments according to the agreed payment schedule.
- Installation work may commence only after receipt of the required advance payment.
- Delayed payments may result in project delays or suspension of services.
- All payments made are subject to applicable taxes.
5. Installation and Project Completion
We strive to complete projects within the estimated timeframe. However, delays may occur due to:
- Weather conditions
- Government approvals
- Supply chain disruptions
- Site accessibility issues
- Force majeure events
We shall not be held liable for delays arising from circumstances beyond our reasonable control.
6. Customer Responsibilities
Customers agree to:
- Provide accurate information regarding the installation site.
- Ensure safe and unrestricted access to the property.
- Obtain necessary permissions from housing societies or authorities where required.
- Cooperate during inspection, installation, and maintenance activities.
7. Warranty
Solar equipment warranties are provided by the respective manufacturers and may vary by product.
Installation workmanship warranty, if applicable, will be provided as stated in the project agreement.
Warranty does not cover:
- Physical damage
- Misuse or negligence
- Unauthorized modifications
- Natural disasters or accidents
- Damage caused by third parties
8. Government Subsidies
Any information regarding government subsidies is provided for general guidance only.
Approval, eligibility, processing time, and subsidy disbursement are solely determined by the relevant government authorities. We do not guarantee subsidy approval or payment.
9. Limitation of Liability
While we make every effort to ensure quality service and accurate information, we shall not be liable for:
- Indirect or consequential losses
- Loss of profits or savings
- Business interruption
- Data loss
- Damages arising from incorrect information provided by customers
Our total liability shall not exceed the amount paid by the customer for the specific service involved.
10. Website Content
The content on this website is provided for informational purposes only.
We reserve the right to:
- Modify website content at any time
- Correct errors or inaccuracies
- Update product specifications without prior notice
11. Intellectual Property
All content on this website, including text, images, graphics, logos, and designs, is the property of Mahadev Newgen Solar and is protected by applicable copyright and intellectual property laws.
Unauthorized reproduction, distribution, or use is prohibited.
12. Third-Party Links
Our website may contain links to third-party websites for informational purposes. We are not responsible for the content, privacy practices, or services offered by such websites.
13. Privacy
Your use of our website is also governed by our Privacy Policy. Any personal information collected will be handled in accordance with applicable privacy laws.
14. Termination
We reserve the right to suspend or terminate access to our website or services if a user violates these Terms and Conditions or engages in unlawful activities.
15. Governing Law
These Terms and Conditions shall be governed by and interpreted in accordance with the laws of India. Any disputes arising under these terms shall be subject to the jurisdiction of the courts in Haryana, India.
16. Contact Information
For any questions regarding these Terms and Conditions, please contact us:
Mahadev Solar Enterprises
Address: Ranwar road, main chowk, sector 35, Karnal
Phone: 7056588347
Email: prayagsingh10101@gmail.com